Terms of Service

1. Agreement to Terms

By accessing or using the Westwood Builders website and services, you agree to be bound by these Terms of Service ("Terms"). If you do not agree to all of these Terms, do not use our website or services. These Terms apply to all visitors, users, and others who access or use our services.

2. Services Description

Westwood Builders provides construction and remodeling services, including but not limited to:

• New home construction
• Residential and commercial remodeling
• Kitchen and bathroom renovations
• Repairs and additions
• Other construction-related services

All services are subject to separate written contracts and agreements that will detail the specific scope of work, pricing, timelines, and terms.

3. Use of Website

You agree to use our website only for lawful purposes and in accordance with these Terms. You agree not to:

• Use the website in any way that violates any applicable federal, state, local, or international law
• Engage in any conduct that restricts or inhibits anyone's use or enjoyment of the website
• Attempt to gain unauthorized access to any portion of the website
• Use any automated system to access the website for any purpose
• Transmit any viruses, malware, or other malicious code

4. Estimates and Quotes

Any estimates or quotes provided through our website or other means are preliminary and subject to change. Final pricing will be determined in a written contract after a thorough assessment of the project. Estimates are valid for 30 days from the date issued unless otherwise specified. We reserve the right to refuse any project at our discretion.

5. Project Contracts

All construction projects require a signed written contract that will include:

• Detailed scope of work
• Project timeline and milestones
• Payment terms and schedule
• Materials specifications
• Warranty information
• Change order procedures

The terms of the individual project contract will govern the specific project and supersede these general Terms of Service in case of any conflict.

6. Payment Terms

Payment terms will be specified in individual project contracts. Generally:

• A deposit may be required to secure project scheduling
• Progress payments will be tied to project milestones
• Final payment is due upon project completion and client acceptance
• Late payments may be subject to interest charges as permitted by law
• We accept various payment methods as specified in the contract

7. Changes and Delays

Any changes to the scope of work must be documented in writing through a change order. Change orders may affect project cost and timeline. We are not responsible for delays caused by weather, material availability, permit delays, client-requested changes, or other circumstances beyond our reasonable control. We will make reasonable efforts to minimize delays and keep you informed of project status.

8. Warranties

Warranty terms for workmanship and materials will be specified in individual project contracts. Manufacturer warranties on materials and equipment will be passed through to the client. Our workmanship warranty covers defects in our work for a specified period as outlined in your contract. Warranties do not cover damage caused by misuse, normal wear and tear, or lack of proper maintenance.

9. Limitation of Liability

To the maximum extent permitted by law, Westwood Builders shall not be liable for any indirect, incidental, special, consequential, or punitive damages resulting from your use of our services or website. Our total liability shall not exceed the amount paid by you for the specific service giving rise to the claim.

10. Intellectual Property

All content on this website, including text, graphics, logos, images, and software, is the property of Westwood Builders or its licensors and is protected by copyright and other intellectual property laws. You may not reproduce, distribute, modify, or create derivative works from any content without our express written permission.

11. Insurance and Licensing

Westwood Builders maintains appropriate licenses and insurance coverage as required by Connecticut law. We will provide proof of insurance upon request. All work will be performed in compliance with applicable building codes and regulations.

12. Dispute Resolution

Any disputes arising from these Terms or our services shall first be attempted to be resolved through good faith negotiation. If negotiation fails, disputes may be resolved through mediation or arbitration as specified in individual project contracts. These Terms shall be governed by the laws of the State of Connecticut.

13. Termination

We reserve the right to terminate or suspend access to our website immediately, without prior notice, for any reason. Upon termination, your right to use the website will immediately cease. Project contracts may include specific termination provisions that will be detailed in the individual contract.

14. Changes to Terms

We reserve the right to modify or replace these Terms at any time. We will provide notice of any material changes by posting the new Terms on this page and updating the "Last Updated" date. Your continued use of the website after any changes constitutes acceptance of the new Terms.

15. Contact Information

If you have any questions about these Terms of Service, please contact us: